Last Updated: 28.08.2025
Welcome to True Layout Interior. These Terms of Service (“Terms”) govern your use of our website and services. By accessing or using our website, you agree to comply with and be bound by these Terms. If you do not agree, please do not use our services.
True Layout Interior provides interior design, consultation, and related services for residential, commercial, and specialised projects. Specific project terms, timelines, and costs will be outlined in individual agreements or contracts.
You agree to use our website for lawful purposes only.
You must not use this website to distribute harmful content, spam, or attempt unauthorized access.
All content, images, and materials on this site are owned by True Layout Interior and cannot be copied or reused without permission.
Initial consultations may be free or chargeable, depending on the scope.
Project timelines and deliverables are shared in advance and may vary based on client requirements, approvals, and availability of materials.
Any changes requested after project confirmation may affect costs and delivery timelines.
Payment terms will be defined in the client’s agreement.
Delayed payments may result in project delays or suspension of services.
All payments are non-refundable unless otherwise specified in the contract.
To ensure smooth project execution, clients agree to:
Provide accurate information and timely approvals.
Ensure site access for our team and contractors.
Make payments as per agreed milestones.
True Layout Interior is not liable for indirect, incidental, or consequential damages arising from the use of our website or services.
While we ensure high-quality work, natural wear and tear, misuse, or unauthorized modifications by third parties are not covered under our responsibility.
All designs, concepts, layouts, and related materials created by True Layout Interior remain our intellectual property unless otherwise agreed in writing. Clients are granted the right to use the final design solely for their space.
In some cases, we may involve third-party vendors or contractors. While we work with trusted partners, we are not liable for their independent actions or delays beyond our control.
We reserve the right to refuse or terminate services at our discretion, especially in cases of non-payment, breach of terms, or misuse of services.
We may update these Terms of Service from time to time. Any changes will be posted on this page with a revised “Last Updated” date. Continued use of our website or services after changes constitutes acceptance of the new Terms.
These Terms are governed by and construed in accordance with the laws of India. Any disputes shall be subject to the jurisdiction of the courts located in [Your City/State].
If you have questions regarding these Terms, please contact us:
📍 Address: Part-1, Nangli Vihar Extn, Najafgarh, New Delhi-110043
📞 Phone: +91 8510919679
📧 Email: info@truelayoutinterior.com
At True Layout Interior, we design spaces that tell your story—authentic, comfortable, and beautifully crafted. Blending timeless layouts with modern elegance, we create interiors where style meets function, and every detail feels like home.
